宗教場(chǎng)所消防系統(tǒng)整改施工合同

宗教場(chǎng)所消防系統(tǒng)整改施工合同合同編號(hào)：__________名稱：____________________地址：____________________法定代表人：________________聯(lián)系電話：________________名稱：____________________地址：____________________法定代表人：________________聯(lián)系電話：________________一、工程內(nèi)容1.1乙方負(fù)責(zé)對(duì)甲方的宗教場(chǎng)所進(jìn)行消防系統(tǒng)整改施工，包括但不限于：（1）檢查消防設(shè)施設(shè)備，確保其符合國(guó)家消防技術(shù)標(biāo)準(zhǔn)；（2）對(duì)消防設(shè)施設(shè)備進(jìn)行維修、更換、增設(shè)，以滿足宗教場(chǎng)所消防安全需求；（3）對(duì)消防系統(tǒng)進(jìn)行調(diào)試、驗(yàn)收，確保其正常運(yùn)行。二、工程質(zhì)量2.1乙方應(yīng)按照消防法律法規(guī)和國(guó)家消防技術(shù)標(biāo)準(zhǔn)進(jìn)行施工，確保工程質(zhì)量。2.2乙方應(yīng)選用符合國(guó)家標(biāo)準(zhǔn)的消防設(shè)施設(shè)備，并提供產(chǎn)品合格證明。2.3工程驗(yàn)收合格后，乙方應(yīng)承擔(dān)不少于一年的質(zhì)保期，質(zhì)保期內(nèi)如有問題，乙方應(yīng)及時(shí)予以解決。三、工程進(jìn)度3.1乙方應(yīng)按照甲方提供的施工計(jì)劃進(jìn)行施工，確保工程按時(shí)完成。3.2乙方應(yīng)提前三天向甲方報(bào)告施工進(jìn)度及下一步計(jì)劃，如需調(diào)整施工計(jì)劃，應(yīng)征得甲方同意。四、工程費(fèi)用4.1乙方向甲方提供的消防設(shè)施設(shè)備及施工費(fèi)用為人民幣（大寫）：____元整（小寫）：_____元。4.2乙方應(yīng)在合同簽訂后七個(gè)工作日內(nèi)，向甲方提供正式發(fā)票。五、付款方式5.1甲方應(yīng)在合同簽訂后七個(gè)工作日內(nèi)，向乙方支付合同總價(jià)款的50%。5.2工程驗(yàn)收合格后，甲方應(yīng)向乙方支付剩余的50%工程款。六、違約責(zé)任6.1乙方未按照約定時(shí)間完成工程的，應(yīng)當(dāng)按照逾期天數(shù)向甲方支付違約金，違約金計(jì)算方式為：違約金=合同總價(jià)款×逾期天數(shù)×0.1%。6.2乙方未按照約定質(zhì)量完成工程的，甲方有權(quán)要求乙方返工、賠償損失。6.3甲方未按照約定時(shí)間支付工程款的，應(yīng)當(dāng)按照逾期天數(shù)向乙方支付違約金，違約金計(jì)算方式為：違約金=當(dāng)期應(yīng)付款項(xiàng)×逾期天數(shù)×0.1%。七、爭(zhēng)議解決7.1本合同履行過程中發(fā)生的爭(zhēng)議，雙方應(yīng)友好協(xié)商解決；協(xié)商不成的，可以向有管轄權(quán)的人民法院提起訴訟。八、其他約定8.1本合同一式兩份，甲乙雙方各執(zhí)一份。8.2本合同自雙方簽字（或蓋章）之日起生效，有效期至工程驗(yàn)收合格之日止。甲方（蓋章）：____________________乙方（蓋章）：____________________甲方代表（簽名）：______________乙方代表（簽名）：______________簽訂日期：________________一、附件列表：1.甲方religiousinstitution消防安全整改方案2.乙方firesafetyfacilityequipmentlistandspecification3.Firesafetyfacilityinspectionandmaintenancerecords4.Firesafetyfacilityrepairandreplacementquotation5.Firesafetyfacilityinstallationanddebuggingreport6.Paymentvouchersandrelatedsupportingdocuments7.Contractacceptancecertificate8.Qualityguaranteecertificate二、違約行為及認(rèn)定：3.Failuretomakepaymentwithintheagreedtime:Identifiedasabreachofcontractifthepaymentisnotmadewithinthetimeframespecifiedinthecontract.4.Failuretoprovidetherequireddocumentsorinformation:Identifiedasabreachofcontractiftherequireddocumentsorinformationarenotprovidedwithinthetimeframespecifiedinthecontract.三、法律名詞及解釋：1.Religiousinstitution:AplaceofworshiporreligiousactivitiesrecognizedandregisteredaccordingtothelawsandregulationsofthePeople'sRepublicofChina.2.Firesafetyfacility:Equipmentanddevicesusedforfireprevention,firecontrol,andfireextinguishinginabuildingorpremise.4.Contractbreach:Failuretoperformanyoftheobligationsunderthecontract,orviolationofanytermsandconditionsofthecontract.四、執(zhí)行中遇到的問題及解決辦法：Solution:Refertothecontractfortheagreedpenaltyfordelayandenforcethepenaltyasperthecontract.Ifthedelayisduetounforeseencircumstances,negotiateanextensionoftheprojecttimeline.3.Paymentdisputes:Solution:Refertothecontractfortheagreedpaymenttermsandenforcethepaymentasperthecontract.Ifthereisadisputeoverpayment,negotiatearesolutionorseeklegalaction.4.Disputeovercontractinterpretation:Solution:Refertothecontractfortheagreeddisputeresolutionmechanism.Ifthedisputecannotberesolvedthroughnegotiation,seeklegalaction.五、所有應(yīng)用場(chǎng)景：1.Religiousinstitutionsthatrequirefiresafetysystemupgradesorrepairs.2.Contractorsorserviceprovidersspecializinginfiresafetysysteminstallation,repair,andmaintenance.3.Legalandinsuranceprofessionalsprovidingadvic